[email protected] +91 - 93437 87741

Terms & Conditions

This Services Agreement (the "Agreement") contains the complete terms and conditions which govern you of Website Design, Development and other Internet-related services provided by TechnoTronixs (the "Services"). As used in this Agreement, "TechnoTronixs" means TechnoTronixs and "Client", "you", or "your" means you. You acknowledge that you have read the Agreement, and you agree to its terms and conditions and all policies posted on the TechnoTronixs site. As referred to in this Agreement, "Site" refers to a World Wide Web site and "TechnoTronixs Site" refers to the Site located at the URL or any other successor Sites owned or maintained by TechnoTronixs.


ACCEPTANCE


The following terms and conditions apply to all website development / design services provided by TechnoTronixs to the Client. It is not necessary for any Client to have signed an acceptance of these terms and conditions for them to apply. If a client accepts a quote, then the Client will be deemed to have satisfied themselves as to the terms applying and have accepted these terms and conditions in full. Please read these terms and conditions carefully. Any purchase or use of our services implies that you have read and accepted our terms and conditions.


PROJECT TERMS


All estimates/quotes are based on our understanding of your requirements and as per given time-frame. Any changes to the functionality including micro-improvements, may incur additional costs accordingly.


By accepting a quote, you agree to and accept the terms and conditions of TechnoTronixs. Acceptance can be verbal, by email, payment of Initiation, signing a quote.


Clients to ensure that we have included all requirements in the quotes/proposals/estimates and that we fully understand their requirements. Clients must provide us with clear guidelines along with the flow or specific details they may require. When such details are not provided, we will proceed with our understanding of the requirements and quote accordingly. At a later stage, if a discrepancy arises, it may lead to additional costs to accommodate the changes. Thus, it is essential that you clarify every aspect of your website development and ensure that you have been quoted on the right requirements.


Any complexity related to specific tasks, must be advised in advance and included in the proposal for costing purposes. We operate in good faith and rely on our clients to disclose the full picture at the time of quotation. Any discrepancy arising due to unclear requirements will not be borne by TechnoTronixs. TechnoTronixs will make every effort to complete the project/changes in the given timeframe. Reasonable delays are accepted if functionalities are redefined or modified.


CHARGES 

 

Charges for services to be provided by TechnoTronixs are defined in the project quotation that the Client receives. The Charges are to paid in four instalments


i)                   An advance payment of twenty-five (25) percent of the total amount.

ii)                 On completion of 30% of the work an amount twenty-five (25) percent of the total amount is to be paid.

iii)               On completion of the remaining 70% of the work another twenty-five (25) percent of the total amount is to be paid.

iv)               On completion of the entire work, the remaining twenty-five (25) percent is to paid.

v)                  The above-mentioned charges are subject to change at the time of project discussion.


ADDITIONAL CHARGES


Any delays at client’s end, may delay the project and proposed timeframes and may incur additional costs. Any re-work on an already completed task will attract additional charges. Any changes in the design after the design approval will incur additional charges. Any modifications requested during the development or after the Go-Live approval will incur additional charges. All additional work, over and above the estimates is charged separately. Under no circumstances will TechnoTronixs be liable for any delays caused by change in the project brief.


PAYMENT


Invoices will be provided by TechnoTronixs upon payment of each instalment. Invoices are normally sent via email; however, the Client may choose to receive hard copy invoices. Invoices are due upon receipt .


ADDITIONAL EXPENSES


Client agrees to reimburse TechnoTronixs for any additional expenses necessary for the completion of the work. Examples would be purchase of special fonts, stock photography etc. These payments are to be made in advance.


WEB BROWSERS


TechnoTronixs makes every effort to ensure websites are designed to be viewed by the majority of visitors. Websites are designed to work with the most popular current browsers (e.g. Firefox, Internet Explorer, Google Chrome, etc.). Client agrees that TechnoTronixs cannot guarantee correct functionality with all browser software across different operating systems.


TechnoTronixs cannot accept responsibility for web pages which do not display acceptably in new versions of browsers released after the website have been designed and handed over to the Client. As such, TechnoTronixs reserves the right to quote for any work involved in changing the website design or website code for it to work with updated browser software.


GENERAL


These Terms and Conditions supersede all previous representations, understandings or agreements. The Client's signature below or payment of an advance fee constitutes agreement to and acceptance of these Terms and Conditions.


DISPUTES/LIABILITY AND INDEMNITY


In an event of a dispute, TechnoTronixs reserves the right to charge the client in full for the work done as well as for the resources spent in managing the dispute. In such an event, TechnoTronixs reserves the right to charge the client without honouring any discounts that were previously honoured in good faith. Under no circumstances will TechnoTronixs be liable for any damages arising from misrepresentation or misinformation.


TechnoTronixs reserves the right to refuse service to any client, if these are not aligned with our business operating principles and policies. TechnoTronixs provides its services as is, without any guarantees on security or other issues leading to loss of data, sale or reputation. We ensure to the best of our ability that our systems and servers are protected from hackers, viruses, intruders and other online and offline problems, however we will not be held liable for any disruption of services if such situation arises.


Client will indemnify and hold TechnoTronixs, its licensors, content providers, service providers, employees, agents, officers, directors, contractors and sub-contractors (the “Indemnified Parties”) harmless from your breach of any of these Terms and Conditions or any other terms, conditions, policies or procedures herein, including, without limitation, any use of content other than as expressly authorized in these Terms and Conditions. Client agrees that the indemnified parties will have no liability in connection with any such breach or unauthorized use, and you agree to indemnify and hold harmless the Indemnified Parties from any and all resulting loss, damages, judgments, awards, costs, expenses, and attorneys’ fees in connection therewith. You will also indemnify and hold the Indemnified Parties harmless from and against any claims brought by third parties arising out of your use of the information obtained from TechnoTronixs.


TechnoTronixs will not be liable for any breach of the agreement which is caused by a matter beyond its reasonable control including but not limited to Act of God, fire, lightning, explosion, war, disorder, flood, earth quake, industrial disputes (whether or not involving their employees), extremely severe weather, or acts of local or central government or other competent authorities.


INTELLECTUAL PROPERTY RIGHTS


All content of this website is a property of TechnoTronixs unless otherwise specified. TechnoTronixs reserves the right to change the content or policies without any prior notice.


The project related copyrights can be transferred to the client at an additional cost, after the full payment of the project and upon signing the Certificate of Acceptance. TechnoTronixs reserves the rights to refuse the transfer of ownership if irregular circumstances arise.


Copyrights handed over to the client do not include rights to re-use the code for another website or re-sell the programming codes for any commercial or non-commercial purposes. In the case of business restructuring or ownership change, ownership of the website may be transferred from one owner to another. New owners are not allowed to re-sell or re-use for any commercial or non-commercial purpose.


In an event of a Webmaster change, site owners are not allowed to display the credits to the new website, unless such time that the website functionality and appearance is changed by over 50% of our original work.

 

LINKS TO THIRD-PARTY WEB SITES


Links on the Site to third party web sites or information are provided solely as a convenience to you. If you use these links, you will leave the Site. Such links do not constitute or imply an endorsement, sponsorship, or recommendation by TechnoTronixs of the third party, the third-party web site, or the information there. TechnoTronixs is not responsible for the availability of any such web sites. TechnoTronixs is not responsible or liable for any such web sites or the content thereon. If you use the links to the web sites of TechnoTronixs affiliates or service providers, you will leave the Site and will be subject to the terms of use and privacy policy applicable to those web sites.


GOVERNING LAW


This agreement shall be governed by the Indian Law. You agree to the sole and exclusive jurisdiction of the Courts in Indore in the event of any dispute of any kind arising from or relating to these Terms & Conditions, TechnoTronix’s Privacy Policy, your use of the Site, or the Content

FORCE MAJEURE


Neither party will be liable to the other for any delay or failure to perform any obligation under these Terms (except for a failure to pay fees) if the delay or failure is due to events which are beyond the reasonable control of such party, such as a strike, blockade, war, act of terrorism, riot, natural disaster, failure or diminishment of power or telecommunications or data networks or services, or refusal of a license by a government agency.

 

SEVERABILITY


In the event any one or more of the provisions of this Agreement shall be held to be invalid, illegal or unenforceable, the remaining provisions of this Agreement shall be unimpaired and the Agreement shall not be void for this reason alone. Such invalid, illegal or unenforceable provision shall be replaced by a mutually acceptable valid, legal and enforceable provision, which comes closest to the intention of the parties underlying the invalid.


ENTIRE AGREEMENT/NO WAIVER 

These Terms & Conditions constitute the entire agreement of the parties with respect to the subject matter hereof. No waiver by TechnoTronixs of any breach or default hereunder shall be deemed to be a waiver of any preceding or subsequent breach or default.


CORRECTION OF ERRORS AND INACCURACY

The Content may contain typographical errors or other errors or inaccuracies and may not be complete or current. TechnoTronixs therefore reserves the right to correct any errors, inaccuracies or omissions and to change or update the Content at any time without prior notice. TechnoTronixs does not, however, guarantee that any errors, inaccuracies or omissions will be corrected.


Update on 18th Dec 2021